Terms And Conditions

Agreeing on Excellence: Read, Understand, and Accept Terms and Conditions.

These Terms and Conditions ("Terms") constitute a legally binding agreement between WireFuture ("Agency") and the Client ("Client"). Please carefully read and understand these Terms before engaging our services.

• 1. Scope of Work and Services

  • 1.1 The Agency will provide software development services as agreed upon in the project proposal or statement of work.

  • 1.2. The scope of work includes project specifications, features, functionalities, deliverables, and any additional services as mutually agreed upon.

• 2. Project Timeline and Milestones

  • 2.1. The Agency will define the project timeline, milestones, and deliverables. Any delays in the project timeline due to unforeseen circumstances will be communicated promptly to the Client.

  • 2.2. The Client agrees to provide necessary feedback, approvals, and resources in a timely manner to avoid delays in project completion.

• 3. Payment Terms

  • 3.1. The Client agrees to pay the Agency as per the agreed payment schedule, outlined in the project proposal or contract.

  • 3.2. Payments are to be made within the specified payment terms, unless otherwise agreed upon in writing.

  • 3.3. In the event of project termination, the Client agrees to pay for completed work up to the termination date.

• 4. Intellectual Property and Ownership

  • 4.1. All intellectual property rights, including copyrights, trademarks, and patents, pertaining to the software developed by the Agency shall remain the exclusive property of the Client upon full payment.

  • 4.2. The Agency retains the right to use the project as part of its portfolio and showcase it for promotional purposes.

• 5. Confidentiality

  • 5.1. The Agency agrees to keep all information provided by the Client confidential and shall not disclose it to any third party without the Client's prior written consent.

  • 5.2. The Client shall treat any proprietary information from the Agency with the same confidentiality and not disclose it without written consent.

• 6. Warranty and Support

  • 6.1. The Agency provides a warranty period for the software as specified in the project documentation. During this period, the Agency will fix any defects free of charge.

  • 6.2. Additional support and maintenance beyond the warranty period will be subject to a separate agreement or on a time and materials basis.

• 7. Limitation of Liability

  • 7.1. The Agency's liability, in any circumstances, shall be limited to the amount paid by the Client for the specific services provided.

  • 7.2. The Agency shall not be liable for any consequential, indirect, or incidental damages arising from the use or inability to use the software.

• 8. Termination of Agreement

  • 8.1. Either party may terminate this agreement with written notice, specifying the reasons for termination.

  • 8.2. In case of termination, the Client shall pay for all services provided up to the termination date.

• 9. Governing Law and Dispute Resolution

  • 9.1. These Terms shall be governed by the laws of Ahmedabad, Gujarat. Any disputes arising from this agreement shall be subject to the exclusive jurisdiction of the courts in Ahmedabad, Gujarat.

• 10. Entire Agreement

  • 10.1. These Terms constitute the entire agreement between the parties and supersedes all prior agreements, written or oral, relating to the subject matter herein.